Title: Curtain Installation Contract
Contract Date: [Insert Date]
Contract Parties:
1、(Hereinafter referred to as "Client")
2、(Hereinafter referred to as "Contractor")
Preamble:
This contract is made by and between the Client and the Contractor, in connection with the installation of curtains at the Client's premises. The Client has requested the Contractor to install curtains at their specified locations, and the Contractor has accepted this request. Both parties hereby agree to the following terms and conditions.
1、Scope of Work:
The Contractor shall install curtains at the following locations: [Insert List of Location]
The Contractor shall provide the following curtain types: [Insert List of Curtain Types]
2、Price and Payment:
The total cost of the curtain installation shall be [Insert Total Cost]. The Client shall make payment in two installments. The first installment of [Insert First Installment] shall be paid upon signing of this contract. The second installment of [Insert Second Installment] shall be paid upon completion of the installation work. All payments shall be made by [Insert Method of Payment].
3、Time and Completion:
The Contractor shall commence the installation work on [Insert Start Date] and shall complete the same on [Insert Completion Date]. The Client shall provide all necessary assistance and cooperation to enable the Contractor to carry out the installation work successfully.
4、Quality and Warranty:
The Contractor shall ensure that the quality of the curtains and installation work are of a high standard and shall provide a warranty period of [Insert Warranty Period] from the date of completion of the installation work. During this warranty period, if any defects or problems occur with the curtains or installation work, the Contractor shall promptly rectify the same at no extra cost to the Client.
5、Termination:
Either party may terminate this contract by giving [Insert Notice Period] days' notice to the other party. In case of termination, the Client shall be entitled to a refund of the second installment payment made, if any, and the Contractor shall be responsible for removing the curtains installed at the Client's premises.
6、General Clauses:
(a) The Client shall have the right to cancel this contract at any time prior to the commencement of the installation work, in which case the Client shall be entitled to a full refund of all payments made.
(b) The Contractor shall not be responsible for any indirect or consequential losses or damages arising out of or in connection with this contract.
(c) This contract shall be governed by the laws of [Insert Country/State] and any disputes arising out of or in connection with this contract shall be subject to the exclusive jurisdiction of the courts of [Insert Country/State].
(d) The invalidity or unenforceability of any provision of this contract shall not affect the validity or enforceability of any other provision.
(e) This contract may be executed in [Insert Language] only, and any translation into another language shall not affect its validity or interpretation.
In Witness Whereof, the parties hereto have executed this Curtain Installation Contract on the date first written above.
Client: ________________________________________________________ (Signature)
Contractor: ___________________________________________________ (Signature)
Articles related to the knowledge points of this article：
Title: Proper Techniques for Using a Tie Clip
Title: The Stylish and Functional Design of a Down Cotton Vest
Title: The Timeless Allure of Silk Scarves - Unraveling the Magic of Real Silk Scarves
The Enchanting World of Suzhou Silk Scarves: An Exquisite Blend of Tradition and Modernity
